Amey has set up a joint venture with drone specialist VTOL Technologies for infrastructure survey work. Above: The Flying Wing The aim is to be able to introduce a new level of surveying technology by 2018. AmeyVTOL will use its own patented unmanned autonomous drone, known as The Flying Wing, which carries ground penetrating radar, high definition video and still, infrared, thermal and light detection and ranging sensors. The Flying Wing can take off and land anywhere, travel long distances at speeds of up to 60km/h and change direction to map the same route over and over, regardless of weather conditions. It also captures data in real time and streaming it live to a data processing engine. AmeyVTOL service development director Richard Butterfield said: “Using this cutting-edge technology to inspect the vital infrastructure that we all rely on is a world first. It will change the way we inspect assets forever; allowing us to assess at the touch of a button, make real-time recommendations and potentially save millions of pounds for our clients.” AmeyVTOL director Mark Shaw added: “Our unique and patented Flying Wing outperforms existing drones and represents the future of aerial inspections. We’re really excited to be introducing this market-leading technology which will revolutionise the asset management industry to deliver repeatable, consistent and accurate inspections as early as 2018.” AmeyVTOL is launch the partnership at the 2016 Farnborough Airshow this week.         This article was published on 13 Jul 2016 (last updated on 13 Jul 2016). Source link

It has been estimated that the total cost to the construction, insurance and transport industries of 2014’s floods was around £2.5bn and the consequences still linger in the form of legal disputes and insurance claims. Jonathan Hyndman looks at what lessons have been learned. Above: The seawall at Dawlish has been rebuilt since collapsing in last year’s floods Many construction projects were, at the very least, hindered and at worst, terminated due to the deluge of flood water last year. Efforts were initially focused upon the clean-up of the sites to allow projects to continue. As time elapses, disputes invariably arise between employers and contractors in relation to project delay and, in particular, whether the contractor is entitled to an extension of time to complete the works and/or a claim for direct loss and expense. Moreover, these disputes are generally hotly contested.  Looking at the provisions of the JCT design and build contract the phrase ‘the devil is in the detail’ immediately springs to mind. In relation  to extensions of time, the contractor is required, as soon as it becomes apparent that the project is being, or is likely to be, delayed, to give notice to the employer of the ‘material circumstances, including the cause or causes of the delay’. The contractor is also required to provide an estimate as to any expected delay to the completion of the works beyond the contractual completion date. Only where the cause of the delay constitutes a ‘relevant event’ the employer is obliged to give an extension of time as it considers fair and reasonable. The term ‘relevant event’ is defined within the JCT suite of contracts as including ‘exceptionally adverse weather conditions’. It is, however, important for both contractors and employers to note that only exceptional, adverse weather will automatically constitute a ‘relevant event’. Whilst the phrase ‘exceptionally adverse weather conditions’ is not defined within the JCT suite of contracts, it is generally accepted that to amount to ‘exceptionally adverse weather conditions’ the adverse weather must, during a calendar month, exceed the long-term average at that time of year and in the location of the project by a significant amount.  Accordingly, under the terms of the JCT form of contract, contractors are required to bear the risks associated with non-exceptional weather conditions and will often take these into account when negotiating the contract sum and the construction programme. ‘Relevant event’ under the JCT contract also includes loss or damage occasioned by any of the ‘Specified Perils’ and force majeure. With flooding both expressly included within the JCT definition of ‘Specified Perils’ and also arguably an event outside the control of the contracting parties, these additional provisions may provide the contractor with alternative grounds for an application for an extension of time where the weather conditions responsible for the delay are not sufficiently exceptional. The position in relation to a contractor’s entitlement to claim direct loss and/or expense incurred as a result of flooding from its employer under the JCT form of contract is, however, somewhat different to its entitlement to an extension of time. Under the JCT form of contract, a contractor will only be entitled to submit a claim for direct loss and/or expense where regular progress of the works has been impeded either as a result of a deferment on the provision of possession of the site by the employer or by a ‘relevant matter’. Crucially, weather conditions, however adverse they may be, do not constitute a ‘relevant matter’ under the JCT form of contract. Consequently, the contractor is not entitled to any additional payments for costs incurred as a result of adverse weather conditions. It is of course standard practice for physical damage to the works and site materials to be protected during construction by an all risks insurance policy. The JCT form of contract requires either the employer or the contractor to maintain all risks insurance in joint names until the earlier of practical completion of the works or the termination of the building contract. Clearly, the extent of any insurance recovery will depend upon the specific wording of the policy, although the Courts have given some guidance on the meaning of a ‘flooding’ for indemnity purposes. The authorities suggest that there must be sufficient volume and suddenness: some abnormal, violent situation, involving a rapid accumulation or sudden release of water from a natural or possibly manmade source. It appears that a slow seepage or build-up of less than around 3 inches of water may be deemed insufficient to trigger insurance cover.  It is also worth considering that it may be possible to bring a claim in nuisance in respect of loss caused by escape of water from a neighbouring property. The duty of nuisance is limited to doing that which is reasonable in all the circumstances to prevent or minimise the known risk of damage or injury to one’s neighbour or to his property. There is also the possibility of a claim against the Environment Agency or utility companies, for example for failure to dredge rivers or sewerage overflow, although it is difficult to establish in practice. Where a statutory authority is entrusted with a mere power (as opposed to positive duty), it cannot be made liable for damage sustained by a member of the public as a result of failure to exercise that power. In exercising a discretionary power, the only duty owed to individuals is not thereby to increase the damage that would have been suffered had they done nothing.   About the author: Jonathan Hyndman is a partner at law firm Rosling King   This article was published on 21 Jan 2015 (last updated on 21 Jan 2015). Source link